Massage in Scranton Pa
Through the years of owning our own Massage Therapy and Hair cutting salon business and multiple properties, I have come across several individuals who were very good and fairly price. This information is brought to you by massage in Scranton.
I wish to share these individuals with you.
Remodeling Jack Anderjack 570-961-3305
Plumbing - Frank Lynott 570 885 9490
Heating oil and propane
Hazen Fuel 570 383 2600
Car repair and service -
Dave Hopkins - 570-563-1334
Chat GPT suggested a contractor contract
Independent Contractor Fixed-price Services Agreement
INDEPENDENT CONTRACTOR FIXED‑PRICE SERVICES AGREEMENT
This Independent Contractor Fixed‑Price Services Agreement (the “Agreement”) is made as of _____________ (“Effective Date”), by and between:
Owner / Client: ________________________________, with an address of ________________________________ (“Owner”), and
Contractor: ________________________________, a ________________________________, with an address of ________________________________ (“Contractor”).
Owner and Contractor may be referred to individually as a “Party” and collectively as the “Parties.”
1. Scope of Work
Contractor shall furnish all labor, supervision, tools, equipment, and materials necessary to complete the following work (the “Work”):
The Work shall be performed in a good and workmanlike manner, consistent with industry standards and all applicable laws, codes, and manufacturer specifications.
2. Schedule, Regular Attendance, and Completion
2.1 Start Date: ____________________
2.2 Substantial Completion Date: ____________________
2.3 Regular Presence Requirement. Contractor shall be present and actively working on the Project no fewer than ___ days per week (excluding lawful holidays, weather delays, or delays approved in writing by Owner) from start until final completion.
2.4 Daily Work Hours (if applicable): ____________________
2.5 Delays. Contractor shall promptly notify Owner in writing of any event that may delay performance. Unexcused absences or failure to maintain regular progress shall constitute a material breach.
3. Contract Price and Payment Terms
3.1 Fixed Price. Owner shall pay Contractor a total fixed price of $______________ (“Contract Price”) for full performance of the Work.
3.2 No Cost Overruns. The Contract Price is firm and not subject to increase for any reason, including underestimated labor or materials, except by a written change order signed by both Parties.
3.3 Payment Schedule:
Initial payment: $______________ upon execution
Progress payment(s): $______________ upon milestones listed below
Final payment: $______________ upon final completion and acceptance
Milestones: _________________________________________________________________
3.4 Retainage. Owner may withhold ___% retainage from each progress payment until final completion.
3.5 No Advance Demands. Contractor shall not demand or accept additional compensation outside this Agreement.
4. Change Orders (Strictly Limited)
Any change to the scope, schedule, or price must be documented in a written change order describing the change and its cost/time impact and must be signed by both Parties before the changed work begins. Oral changes are void.
5. Clean‑Up and Protection of Property
5.1 Daily Clean‑Up. Contractor shall keep the Project site reasonably clean at the end of each workday and shall remove debris, trash, and unused materials.
5.2 Final Clean‑Up. Upon completion, Contractor shall leave the site broom‑clean and free of debris.
5.3 Damage. Contractor shall promptly repair or replace, at Contractor’s expense, any damage caused by Contractor or its workers.
6. Personnel, Lawful Employment, and Insurance
6.1 Qualified Workers Only. Contractor warrants that all workers are properly trained, legally authorized to work, and competent to perform the Work.
6.2 Independent Contractor Status. Contractor is solely responsible for wages, taxes, benefits, and supervision of its workers.
6.3 Workers’ Compensation & Insurance. Contractor shall maintain, at its own expense:
Workers’ Compensation insurance as required by law;
General Liability insurance with minimum limits of $______________ per occurrence;
Any other insurance required by law or reasonably requested by Owner.
Certificates of insurance naming Owner as an additional insured shall be provided before work begins.
6.4 Compliance with Hiring Laws. Contractor represents and warrants compliance with all federal and state employment laws, including lawful hiring and verification requirements.
6.5 Background & Safety Standards. To the extent permitted by law, Contractor shall ensure workers assigned to the Project meet reasonable safety and conduct standards appropriate for work at a private residence or jobsite.
7. Quality of Work and Correction
7.1 Standard of Care. Work shall meet or exceed generally accepted industry standards.
7.2 Correction of Defective Work. Contractor shall promptly correct, at no cost to Owner, any defective or non‑conforming work.
7.3 Warranty. Contractor warrants the Work for a period of ___ months from final completion.
8. Inspections and Approval
Owner may inspect the Work at reasonable times. Payment does not constitute acceptance of defective work.
9. Termination
9.1 For Cause. Owner may terminate this Agreement upon written notice if Contractor fails to maintain regular progress, violates this Agreement, or performs substandard work and fails to cure within ___ days.
9.2 Effect of Termination. Owner shall pay only for properly completed work accepted as of the termination date, less damages and retainage.
10. Lien Waivers
Contractor shall provide conditional and final lien waivers from itself and all subcontractors or suppliers as a condition of payment.
11. Dispute Resolution
Any dispute shall first be addressed through good‑faith negotiation. If unresolved, disputes shall be resolved by ____________________ (mediation/arbitration/court) in ____________________.
12. Indemnification
Contractor shall indemnify and hold harmless Owner from claims, damages, losses, and expenses arising from Contractor’s work, negligence, or breach of this Agreement.
13. Governing Law
This Agreement shall be governed by the laws of the State of ____________________.
14. Entire Agreement
This Agreement constitutes the entire agreement between the Parties and may be amended only in writing signed by both Parties.
15. Signatures
Owner: ________________________________ Date: _____________
Contractor: ____________________________ Date: _____________
Practical Contract Safeguards (Recommended)
Milestone‑based payments with retainage to maintain leverage.
Daily/weekly presence requirement tied to default.
No‑extras clause with strict written change orders only.
Proof of insurance & workers’ comp before start.
Lien waivers to avoid payment disputes.
Liquidated damages (optional) for unexcused delays.
Termination for cause with cure period.
Final payment conditioned on clean‑up, inspection, and waivers.